UNMH SRMC Construction Manager at Risk (CMAR) - Sterile Processing Department Renovation Project - RFP-2632-26 (2026)
University Of New Mexico-Los Alamos CampusHigher Ed · Los Alamos, NM- Due
- Jun 9, 2026
- Deadline passed
- Posted
- May 18, 2026
- Primary contact
- Mary Stuart
- (505) 277-8611
The 30-second brief
University of New Mexico Hospital seeks a Construction Manager at Risk (CMAR) for the Sandoval Regional Medical Center (SRMC) Sterile Processing Department (SPD) Renovation Project on the 2nd floor, solicitation RFP-2632-26. The scope includes renovating the decontamination room to accept new or relocated sterile processing equipment complying with NFPA 101 2012 and New Mexico Healthcare Authority, early work packages for water treatment requirements and volume measurements, removal of an un-used cart wash, installation of four new Steris disinfectors, plumbing for a second sonic irrigator, floor sink discharge evaluation, and relocating existing endoscopy scope equipment. Submission deadline is June 9, 2026, at 3:00 PM MDT via email to [email protected]. Minimum qualifications require a contractor's license under the Construction Industries Licensing Act, registration pursuant to Section 13-4-13.1 NMSA 1978, and minimum bonding capacity for the entire project value. Contract completion by June 30, 2026, with liquidated damages of $5,000 per day.
Past General Contractor Performance (5 Points), Past General Contractor Experience (5 Points), Presentation of the Project Team (5 Points), Discuss the major challenges (10 Points), Ability of the Respondent (5 Points), Respondent's experience and utilization (5 Points), Recent, current and projected workloads (5 Points)
Get notified when University Of New Mexico-Los Alamos Campus posts the next one.
Get alerts freeFree account · 30-second setup · No credit card
Summary
University of New Mexico Hospital seeks a Construction Manager at Risk (CMAR) for the Sandoval Regional Medical Center (SRMC) Sterile Processing Department (SPD) Renovation Project on the 2nd floor, solicitation RFP-2632-26.
The scope includes renovating the decontamination room to accept new or relocated sterile processing equipment complying with NFPA 101 2012 and New Mexico Healthcare Authority, early work packages for water treatment requirements and volume measurements, removal of an un-used cart wash, installation of four new Steris disinfectors, plumbing for a second sonic irrigator, floor sink discharge evaluation, and relocating existing endoscopy scope equipment. Submission deadline is June 9, 2026, at 3:00 PM MDT via email to [email protected]. Minimum qualifications require a contractor's license under the Construction Industries Licensing Act, registration pursuant to Section 13-4-13.1 NMSA 1978, and minimum bonding capacity for the entire project value. Contract completion by June 30, 2026, with liquidated damages of $5,000 per day.
EVALUATION CRITERIA
REQUIRED ATTACHMENTS
13- Conflict of Interest Form
- Proposer Qualifications for General Contractor packet
- Letter of interest
- State of New Mexico Resident Preference Number certificate
- Resident Veterans Certification
- Organization form
- Licensing form
- Surety form
- Safety form
- Safety Plan
- Insurance & Claims History form
- Quality Assurance form
- Labor Code Violations form
- Submit to
- [email protected]
- Scope location
- Rio Rancho, NM
- Reported agency
- University of New Mexico Hospital
Questions about this RFP
How do I respond to this RFP from University Of New Mexico-Los Alamos Campus?
Review the full solicitation document for submission requirements, evaluation criteria, and deadlines. The submission deadline is June 9, 2026. Be sure to include all required attachments as outlined in the solicitation. Submissions should be delivered to: [email protected]. For questions, contact Mary Stuart.
Can small businesses or minority-owned firms bid on this RFP?
Most government agencies, including University Of New Mexico-Los Alamos Campus in NM, encourage participation from small businesses, minority-owned, women-owned, and disadvantaged business enterprises (MBE/WBE/DBE). Check the full solicitation for any small business participation goals.
What happens after the RFP submission deadline?
After the deadline, the issuing agency reviews all submissions against the stated evaluation criteria. This typically includes a compliance check, technical evaluation, cost analysis, and may involve oral presentations with shortlisted vendors.
Can I ask questions about this solicitation before submitting?
Yes, most solicitations allow vendors to submit questions during a designated period. The primary contact is Mary Stuart at (505) 277-8611. Questions and answers are typically shared with all prospective bidders.
Show 4 more questions
What are the evaluation criteria for this solicitation?
This solicitation includes specific evaluation criteria that will be used to score proposals. The criteria include: "Past General Contractor Performance (5 Points), Past General Contractor Experience (5 Points), Presentation of the Project Team (5 Points), Discuss the major challenges (10 Points), Ability of the Res..." Vendors should carefully align their proposals with each criterion to maximize their score.
Where can I find more RFPs from University Of New Mexico-Los Alamos Campus?
All active and historical solicitations from University Of New Mexico-Los Alamos Campus are tracked and searchable. As a higher ed agency, University Of New Mexico-Los Alamos Campus regularly publishes solicitations. Visit the agency profile to see current open bids, past contracts, vendor relationships, and decision-maker contacts.
What documents are required to bid on this RFP?
Requirements vary by solicitation, but common documents include a technical proposal, cost/price proposal, proof of insurance, relevant certifications, past performance references, and any forms specified in the solicitation. This solicitation specifically requires the following attachments: Conflict of Interest Form, Proposer Qualifications for General Contractor packet, Letter of interest, State of New Mexico Resident Preference Number certificate, Resident Veterans Certification, Organ. Review the full document from University Of New Mexico-Los Alamos Campus for the complete list.
What is the scope of this project?
This solicitation defines a specific project scope. The scope covers the following locations: Rio Rancho, NM. Review the full solicitation for detailed scope requirements.