Virginia Passenger Rail Authority - Leeland Road Bridge Reconstruction RFQ 2024 - 1-008-24-0003
- Due
- Nov 1, 2024
- Deadline passed
- Posted
- Aug 15, 2024
- Duration
- 52 months
- Primary contact
- Jason Lofgreen
- (804) 750-5680
Know who Virginia Passenger Rail Authority (VPRA) buys from before you write a word.
Every vendor contract, renewal date and decision maker at this agency, in one place.
Set up in 30 seconds · No credit card
THE 30-SECOND BRIEF
The Virginia Passenger Rail Authority is issuing a Request for Qualifications (RFQ) to obtain Statements of Qualification (SOQs) from firms interested in serving as the Design-Builder for the Leeland Road (SR-626) bridge reconstruction project in Stafford County, Virginia. The project involves replacing the existing bridge (Virginia Structure No. 6062, Federal Structure ID 18141) carrying SR-626 over CSX Transportation railroad tracks to provide space for a third railroad track under the bridge while preserving space for a fourth track. Major scope items include bridge substructure and superstructure construction, roadway construction, demolition of existing bridge structures, retaining walls, drainage, stormwater management, utility relocations, environmental compliance, geotechnical investigations, survey, and maintenance of traffic with full bridge closure and detours. SOQs are due by November 1, 2024 at 2:00 p.m. Eastern Time, submitted via email to [email protected]. Respondents must be prequalified under VDOT's Highway Contractor Prequalification Program.
Statement of Qualifications (SOQs) from firms interested in serving as the Design-Builder for design and construction of the Leeland Road Bridge Reconstruction project.
Experience of Respondent (35 points), Key Personnel and Organization (35 points), Quality Management (15 points), Understanding of Project and Design-Build (15 points)
SUMMARY
The Virginia Passenger Rail Authority is issuing a Request for Qualifications (RFQ) to obtain Statements of Qualification (SOQs) from firms interested in serving as the Design-Builder for the Leeland Road (SR-626) bridge reconstruction project in Stafford County, Virginia.
The project involves replacing the existing bridge (Virginia Structure No. 6062, Federal Structure ID 18141) carrying SR-626 over CSX Transportation railroad tracks to provide space for a third railroad track under the bridge while preserving space for a fourth track. Major scope items include bridge substructure and superstructure construction, roadway construction, demolition of existing bridge structures, retaining walls, drainage, stormwater management, utility relocations, environmental compliance, geotechnical investigations, survey, and maintenance of traffic with full bridge closure and detours. SOQs are due by November 1, 2024 at 2:00 p.m. Eastern Time, submitted via email to [email protected]. Respondents must be prequalified under VDOT's Highway Contractor Prequalification Program.
EVALUATION CRITERIA
REQUIRED DELIVERABLES
Statement of Qualifications (SOQs) from firms interested in serving as the Design-Builder for design and construction of the Leeland Road Bridge Reconstruction project.
REQUIRED ATTACHMENTS
Form A (Acknowledgement of Receipt of RFQ, Addenda, and Responses to Questions), Form B (Respondent's Organization Information), Organizational agreement or material terms, Form C (Principal Participant and Lead Designer Certification), Form D (Conflict of Interest Disclosure), Surety Letter, Material change disclosure, Evidence of VDOT prequalification, 2-Page Executive Summary, Form E (Project Experience Description), Narrative, Form F (Key Personnel), Key Personnel resumes, Form G (Subcontractor Information), Subcontractor description, Organizational Chart and description, Quality management narrative, Understanding of Project and Design-Build narrative, Form H (Affidavit of Non-Collusion), Form I (Certification Regarding Lobbying), Form J (Certification Regarding Debarment), Form L (Proprietary / Confidential Information Designation)
- Submit to
- [email protected]
- Scope location
- Stafford County, VA
- Reported agency
- Virginia Passenger Rail Authority
Questions about this RFP
How do I respond to this RFQ from Virginia Passenger Rail Authority (VPRA)?
Review the full solicitation document for submission requirements, evaluation criteria, and deadlines. The submission deadline is November 1, 2024. The solicitation specifies required deliverables that must be addressed in your response. Be sure to include all required attachments as outlined in the solicitation. Submissions should be delivered to: [email protected]. For questions, contact Jason Lofgreen.
Can small businesses or minority-owned firms bid on this RFQ?
Most government agencies, including Virginia Passenger Rail Authority (VPRA) in VA, encourage participation from small businesses, minority-owned, women-owned, and disadvantaged business enterprises (MBE/WBE/DBE). Check the full solicitation for any small business participation goals.
What happens after the RFQ submission deadline?
After the deadline, the issuing agency reviews all submissions against the stated evaluation criteria. This typically includes a compliance check, technical evaluation, cost analysis, and may involve oral presentations with shortlisted vendors.
Can I ask questions about this solicitation before submitting?
Yes, most solicitations allow vendors to submit questions during a designated period. The primary contact is Jason Lofgreen at (804) 750-5680. Questions and answers are typically shared with all prospective bidders.
What are the key deliverables?
The solicitation specifies the following deliverables: Statement of Qualifications (SOQs) from firms interested in serving as the Design-Builder for design and construction of the Leeland Road Bridge Reconstruction project.. Proposals should clearly address how each deliverable will be met.
Can I search RFQs like this in ChatGPT or Claude?
Yes. Civic IQ has an MCP server that connects ChatGPT, Claude and other AI assistants to live Civic IQ data: open RFPs, pre-RFP signals from public meetings, awarded contracts and agency decision-makers across 100,000+ US public agencies. Add https://beta.mcp.civiciq.com/mcp as a connector (in ChatGPT under Settings > Apps & Connectors, in Claude under Settings > Connectors) and sign in with a free Civic IQ account at civiciq.com/mcp.
Show 5 more questions
What are the evaluation criteria for this solicitation?
This solicitation includes specific evaluation criteria that will be used to score proposals. The criteria include: "Experience of Respondent (35 points), Key Personnel and Organization (35 points), Quality Management (15 points), Understanding of Project and Design-Build (15 points)" Vendors should carefully align their proposals with each criterion to maximize their score.
Where can I find more RFPs from Virginia Passenger Rail Authority (VPRA)?
All active and historical solicitations from Virginia Passenger Rail Authority (VPRA) are tracked and searchable. As a state agency, Virginia Passenger Rail Authority (VPRA) regularly publishes solicitations. Visit the agency profile to see current open bids, past contracts, vendor relationships, and decision-maker contacts.
What is the contract term for this solicitation?
The anticipated contract term is 52 months. Contract terms may include renewal options.
What documents are required to bid on this RFQ?
Requirements vary by solicitation, but common documents include a technical proposal, cost/price proposal, proof of insurance, relevant certifications, past performance references, and any forms specified in the solicitation. This solicitation specifically requires the following attachments: Form A (Acknowledgement of Receipt of RFQ, Addenda, and Responses to Questions), Form B (Respondent's Organization Information), Organizational agreement or material terms, Form C (Principal Participa. Review the full document from Virginia Passenger Rail Authority (VPRA) for the complete list.
What is the scope of this project?
This solicitation defines a specific project scope. The scope covers the following locations: Stafford County, VA. Review the full solicitation for detailed scope requirements.